Terms and Conditions

Effective Date: October 05, 2024

Welcome to Solar n Battery Solutions. These Terms and Conditions govern your use of our website and the services we provide. By accessing or using our website, you agree to comply with and be bound by the following terms. If you do not agree with these terms, please refrain from using our services or website.

1. Introduction

Solar n Battery Solutions is committed to providing solar power systems, battery storage solutions, and related services. These terms apply to all users of our website and customers of our services.

2. Use of the Website

2.1. You agree to use our website for lawful purposes only and in accordance with these terms.
2.2. You are prohibited from using the website for any unlawful or harmful activity, including but not limited to data mining, unauthorized use, or causing any disruption to the website.

3. Services and Products

3.1. Solar n Battery Solutions provides solar products, including solar panels, inverters, and battery systems.
3.2. All products are subject to availability. We reserve the right to modify or discontinue any product or service without prior notice.
3.3. Our services include installation and maintenance of solar systems. The scope of work will be detailed in a written agreement provided prior to installation.

4. Pricing and Payment

4.1. All prices displayed on our website or provided in quotations are in Australian dollars (AUD) and include GST unless otherwise stated.
4.2. Payment terms will be outlined in the sales agreement, and payment must be made in accordance with those terms. Late payments may incur interest and additional fees.
4.3. We reserve the right to change our prices at any time, but any changes will not affect orders that have already been accepted.

5. Installation and Delivery

5.1. Solar n Battery Solutions will provide an estimated installation and delivery date at the time of the order. While we strive to meet the estimated timelines, unforeseen circumstances may cause delays.
5.2. You agree to provide safe and reasonable access to the property for installation. Failure to do so may result in delays or additional charges.
5.3. Upon installation, you are responsible for ensuring the safety and proper maintenance of the installed equipment.

6. Warranties

6.1. Our products come with warranties as specified in the product descriptions or individual agreements. Typically, solar panels come with a 25-year performance warranty, and inverters come with a 10-year warranty.
6.2. Warranties do not cover damage caused by improper use, unauthorized modifications, or environmental factors beyond our control.

7. Limitation of Liability

7.1. Solar n Battery Solutions shall not be liable for any indirect, incidental, or consequential damages arising from the use of our website, products, or services.
7.2. Our total liability to you for any claim shall not exceed the amount paid by you for the product or service in question.

8. Intellectual Property

8.1. All content on our website, including text, graphics, logos, and images, is the property of Solar n Battery Solutions or its content suppliers and is protected by intellectual property laws.
8.2. You may not reproduce, distribute, or display any part of the website without prior written consent from us.

9. Privacy Policy

Your privacy is important to us. Please review our [Privacy Policy](insert privacy policy link) to understand how we collect, use, and protect your personal information.

10. Cancellation and Refund Policy

10.1. Cancellations must be made in writing within a specified period outlined in the individual agreement.
10.2. Refunds will be processed according to our refund policy, which will be provided at the time of purchase or order confirmation.

11. Governing Law

These Terms and Conditions are governed by and construed in accordance with the laws of South Australia. Any disputes arising from or related to these terms shall be resolved in the courts of South Australia.

12. Amendments

We reserve the right to update or modify these Terms and Conditions at any time without prior notice. Changes will be effective immediately upon posting on our website. Your continued use of the website or services following any changes signifies your acceptance of the updated terms.

13. Contact Information

If you have any questions regarding these Terms and Conditions, please contact us at:
Email: support@peaceelectrical.com.au
Phone: 040 375 4245
Address: 1/7 Russel terrace Woodville 5011